Last Updated: June 2026
Welcome to Adiva Tech Services Pvt. Ltd. By accessing our website or using our services, you agree to the following Terms of Service.
1. Acceptance of Terms
By accessing our website, requesting quotations, purchasing services, or engaging with our team, you agree to be bound by these Terms of Service.
2. Services Offered
Adiva Tech Services may provide:
- PCB Design
- PCB Assembly
- Embedded Systems Development
- Firmware Development
- Product Prototyping
- ODM Services
- OEM Manufacturing
- Product Design
- Engineering Consultation
- Electronics Manufacturing Services
- Custom Technology Solutions
3. Quotations and Pricing
- All quotations are valid for the period specified in the quotation.
- Prices may change due to component availability, supplier pricing, shipping costs, or project scope changes.
- Additional work outside the agreed scope may incur additional charges.
4. Client Responsibilities
Clients agree to:
- Provide accurate project requirements.
- Supply necessary documentation and specifications.
- Obtain required licenses and permissions for their products.
- Review and approve project deliverables within reasonable timeframes.
Delays caused by missing information may impact project timelines.
5. Intellectual Property
Unless otherwise agreed in writing:
- Clients retain ownership of their proprietary information.
- Adiva Tech Services retains ownership of its internal tools, methodologies, libraries, frameworks, and manufacturing processes.
- Custom project ownership shall be governed by the applicable project agreement.
6. Confidentiality
We respect the confidentiality of client information and will take reasonable measures to protect proprietary project data.
Where necessary, separate Non-Disclosure Agreements (NDAs) may be executed.
7. Manufacturing Variations
Electronic manufacturing may involve acceptable industry-standard tolerances.
Minor variations in:
- Component markings
- PCB color
- Surface finish
- Mechanical appearance
shall not be considered defects if functionality remains unaffected.
8. Limitation of Liability
To the maximum extent permitted by law:
- Adiva Tech Services shall not be liable for indirect, incidental, special, or consequential damages.
- Our total liability shall not exceed the amount paid by the client for the specific service giving rise to the claim.
9. Warranty
Unless otherwise specified in writing:
- Services are provided on a best-effort basis.
- Warranty coverage, if applicable, will be specified in the project proposal or invoice.
10. Project Delays
Estimated delivery dates are provided in good faith.
Adiva Tech Services shall not be liable for delays caused by:
- Supplier shortages
- Customs delays
- Shipping disruptions
- Force majeure events
- Client-requested changes
11. Prohibited Use
Clients shall not use our services for:
- Illegal activities
- Unauthorized surveillance
- Intellectual property infringement
- Activities violating local, national, or international laws
12. Governing Law
These Terms shall be governed by and interpreted under the laws of India.
Any disputes shall be subject to the jurisdiction of the courts located in Delhi, India.
13. Changes to Terms
We reserve the right to update these Terms of Service at any time. Updated versions will be posted on our website with the revised effective date.
14. Contact Information
Adiva Tech Services Pvt. Ltd.
Website: Adiva Technology Website
Email: contact@adivatechnology.com